Delay: Choosing the right method for your dispute
How should you analyse delay? Which delay analysis method is best? What options are available?
When a delay occurs on a project, analysing cause and effect is vital to understanding where liability lies. Delay analysis (sometimes called Forensic Planning) is something which some refer to as a ‘dark art’. Arguably because it’s often misunderstood by those who carry it out or claim to understand it. This article aims to set out some of the key elements to consider when undertaking an analysis or working with an analyst to demonstrate delay.
Firstly, you need to know that there are many different methods of delay analysis available. There are at least six, arguably more, depending upon who you speak to.
But how do you know which is most appropriate for your project and where do you start?
For acceptance by the courts or a tribunal, an analysis should use a logical, methodical and calculated method of assessment. However, there is still no ‘best method’. No single analysis applies to every dispute. Tribunals have differing views on the best approach to take.
Factors to be considered include:
- The circumstances of the dispute
- The contract provisions for Extension of Time
- The type of delays experienced
- The records available.
The Society of Construction Law provides some guidance on choosing an appropriate method in its Delay and Disruption Protocol.
Timing is everything…
The first thing to establish is the timing of the analysis. Do you need to use a prospective (looking forward to what will happen) or retrospective (looking back at what’s happened) method?
A prospective analysis such as ‘Impacted As Planned’, or ‘Time Impact Analysis’ is often used whilst the project is still ongoing. This can help assess the impact a delaying event will have on the future completion date. You can also use prospective methods on on completed projects. However, take care. Ensure the ‘theoretical’ prospective analysis corresponds with the ‘actual’ facts.
Should the works be complete, a retrospective method of analysis is often preferable. Examples of the titles of these include; As Planned v As Built Windows or Timeslice Windows. At this point in time, you will know the length of the delay to the completion date. You should also have access to as-built information, allowing you to assess impacts to the ‘as-built’ critical path(s).
Tribunals are tending to move towards a preference for retrospective methods when dealing with delay analysis in post-completion disputes. The SCL Protocol also now adopts this preference for retrospective methods of analysing delay when the works are complete.
How complex is the dispute?
The next point to consider is the complexity of the project and the dispute. Sometimes a simple analysis is enough to explain the delays suffered and the liability for each.
When a dispute is complex, it’s important to keep the analysis and report documents succinct and at a reasonably high level. Remember to keep the main narrative simple and easy to understand for a layperson. This is a crucial role of a delay expert. However, it remains critical to include detailed supporting information in clear appendices. Much like approaching a maths exam, it’s crucial that the working out is clear and understandable.
Equally, a complex delay analysis would not be worthwhile on a simple dispute. The time and cost associated with a complex delay analysis might not be proportionate to the value of the dispute in hand.
When conducting your analysis, whichever method you choose, remember that facts are king (or for balance, queen).
Head over to this page to download out top tips for a successful Extension of Time claim. We look at what needs to be demonstrated to prove delay to progress or completion of the works.
This article was originally written by Tom Francis on Decipher Group’s website
Delay analysis is one of the modules covered in our Construction Claims e-course. Click here to find out more and see the full list of modules.